Terms of Service
Last Updated: June 4, 2026
1. Agreement to Terms
By accessing our website www.mellowmango.in or engaging Mellow Mango ("we," "our," "us") for services, you agree to comply with and be bound by these Terms of Service. If you do not agree to these terms, please do not access our website or engage our services.
2. Services and Scope of Work
Mellow Mango operates as a creative studio providing custom website builds, business tools, dashboards, automations, and content systems. The specific deliverables, timelines, milestones, and fees for any project will be defined in a separate Project Proposal or Scope of Work document agreed upon by both parties before work begins.
3. Project Payments and Milestones
Clients agree to the payment schedules and milestones detailed in the Project Proposal:
- Upfront Deposit: Work begins only after the agreed deposit has been paid and cleared.
- Milestone Payments: Remaining payments are tied to deliverables. Delays in feedback or assets from the client may adjust completion dates but do not negate payment obligations.
- Late Payments: We reserve the right to pause work on any project if invoice payments are overdue.
4. Client Responsibilities and Content
To ensure timely delivery, the client agrees to provide necessary copy, branding assets, images, API access, and feedback within the specified timelines. We are not responsible for delays caused by missing client inputs or technical issues on client-owned third-party platforms.
5. Intellectual Property and Asset Ownership
Ownership of custom code, design files, layouts, and copy is structured as follows:
- During the Project: All code, graphics, and assets remain the property of Mellow Mango until full and final payment is received.
- Upon Final Payment: Intellectual property rights for custom code, website files, and designs delivered to the client transfer completely to the client.
- Third-Party Components: Licenses for third-party scripts, libraries, fonts, or stock media remain subject to their respective creators' terms.
6. Revisions, Support, and Changes
Every project includes a defined revision window as specified in the proposal. Requests for new features, structural revisions, or changes outside the agreed Scope of Work will be quoted separately as a Change Request.
7. Limitation of Liability
Mellow Mango will not be liable for any direct, indirect, incidental, or consequential damages resulting from website downtime, server interruptions, third-party API changes, data loss, or the performance of tools, dashboards, or automations shipped to the client.
8. Governing Law
These Terms of Service are governed by and construed in accordance with the laws of India. Any disputes arising under these terms shall be subject to the exclusive jurisdiction of the courts located in Kerala, India.
9. Contact Information
If you have any questions or require clarification on these Terms, please contact us at: